Last Updated: 12 October 2026
Welcome to Capps Solution W.L.L (“Company”, “we”, “us”, or “our”). These Terms and Conditions (“Terms”) govern your use of our website (www.cappssolution.com) and the software development, digital, and related services we provide.
By accessing our website or engaging our services, you agree to be bound by these Terms. If you do not agree, please do not use our website or services.
1. Company Information
Capps Solution W.L.L
Muharraq, Kingdom of Bahrain
Email: info@cappssolution.com
Phone: +973 6678 6643
2. Services
We provide custom software development, website development, mobile application development, POS & billing systems, ERP solutions, CRM solutions, AI development, UI/UX design, cloud solutions, API integration, SEO, SEM, social media marketing, email marketing, and related IT consulting services.
All services are provided subject to a separate written proposal, quotation, or Statement of Work (SOW) agreed between the parties.
3. Acceptance of Terms
By using our website, submitting an inquiry, or signing a proposal/SOW, you confirm that you have read, understood, and agreed to these Terms.
4. Client Responsibilities
You agree to:
– Provide accurate and complete information required for the project
– Respond to requests for feedback and approvals in a timely manner
– Ensure you have the necessary rights to any materials, content, or data you provide to us
– Make payments according to the agreed schedule
Delays caused by the client may result in revised timelines and additional charges.
5. Payment Terms
– Payments are due as specified in the quotation or SOW (usually advance + milestone-based)
– All prices are exclusive of VAT or any applicable taxes unless stated otherwise
– Late payments may incur interest or suspension of work
– Refunds (if any) are governed by the specific project agreement
6. Intellectual Property
– Upon full payment, you own the final delivered software, designs, and source code as specified in the SOW
– We retain ownership of our pre-existing tools, frameworks, libraries, methodologies, and any reusable components
– We reserve the right to showcase completed projects in our portfolio unless you request otherwise in writing
7. Confidentiality
Both parties agree to keep confidential any proprietary or sensitive information shared during the project, except where disclosure is required by law.
8. Warranties and Limitation of Liability
– We deliver services with reasonable skill and care
– We do not guarantee that software will be completely error-free or uninterrupted
– Our total liability under any project shall not exceed the total fees paid by you for that project
– We are not liable for indirect, incidental, or consequential damages
9. Project Timeline and Delays
Timelines provided are estimates. We are not responsible for delays caused by client feedback, third-party services, force majeure, or circumstances beyond our reasonable control.
10. Termination
Either party may terminate a project as per the terms in the SOW. Upon termination, you remain liable for all work completed and expenses incurred up to the termination date.
11. Website Use
You may not:
– Use the website for any unlawful purpose
– Attempt to gain unauthorized access to our systems
– Copy, scrape, or misuse content from the website without permission
12. Governing Law
These Terms shall be governed by and construed in accordance with the laws of the Kingdom of Bahrain. Any disputes shall be subject to the exclusive jurisdiction of the courts of Bahrain.
13. Changes to These Terms
We may update these Terms from time to time. The updated version will be posted on this page with a revised “Last Updated” date.
14. Contact Us
For any questions regarding these Terms, please contact us at:
Email: info@cappssolution.com
Phone: +973 6678 6643